装修合同范本六篇.docx

装修合同范本六篇
文章一：装修合同范本一
中文正文：
装修合同
甲方：（委托方）______________
乙方：（施工方）______________
鉴于甲方欲对其物业进行装修，经双方友好协商，达成如下协议：
一、装修工程范围：
1.装修项目：______________
2.装修内容：______________
3.装修工期：______________
4.装修费用：______________
5.装修质量标准：______________
二、费用支付方式：
1.甲方应在签订合同之日支付装修款项的____%作为定金，余款在工程竣工验收合格后支付。
2.如因甲方原因造成施工进度延误，甲方应支付额外的延期费用。
三、工程保修：
1.乙方承诺所施工程质量符合国家标准，保修期为__________。
2.保修期内，由于施工质量问题导致的损坏，乙方将免费提供维修服务。
四、违约责任：
1.若一方发现另一方违约行为，应当书面通知对方，故意造成损害的一方应承担相应责任。
2.因不可抗力导致合同无法履行，双方可协商解除合同，已支付的定金不予退还。
五、其他约定事项：
1.本合同一式两份，甲乙双方各执一份，自双方签字盖章生效。
2.合同如有争议，将协商解决，协商不成的，提交本地法院诉讼解决。
甲方（盖章）： 乙方（盖章）：
签订日期：______________
英文正文：
Decoration Contract
Party A: (Client) ______________
Party B: (Contractor) ______________
In view of Party A's desire to decorate its property, after friendly negotiation between both parties, the following agreement is reached:
Scope of decoration project:
1. Decoration project: ______________
2. Decoration content: ______________
3. Decoration period: ______________
4. Decoration cost: ______________
5. Decoration quality standards: ______________
Payment method:
1. Party A shall pay ____% of the decoration fee as a deposit on the day of signing the contract, and the balance shall be paid after the completion of the project and acceptance.
2. If the construction progress is delayed due to Party A's reasons, Party A shall pay additional delay fees.
Engineering warranty:
1. Party B promises that the quality of the construction project meets national standards, with a warranty period of ______________.
2. During the warranty period, Party B will provide free repair services for damages caused by construction quality issues.
Breach of contract:
1. If one party discovers a breach by the other party, written notice shall be given, and the party intentionally causing damage shall bear corresponding responsibilities.
2. In the event that the contract cannot be fulfilled due to force majeure, both parties may negotiate to terminate the contract, and the deposit already paid shall not be refunded.
Other agreed matters:
1. This contract is made in duplicate, with Party A and Party B each holding one copy, and it shall take effect upon the signatures and seals of both parties.
2. In case of disputes arising from the contract, they shall be resolved through negotiation, and if no agreement can be reached, the matter shall be submitted to the local court for litigation.
Party A (Seal): __________
Party B (Seal): __________
Date of Signing: ______________
文章二：装修合同范本二
中文正文：
装修合同
甲方：（业主）______________
乙方：（设计师）______________
为保证双方权益，特订立如下合同：
一、装修工程概况：
1.业主将住宅装修工程委托设计师乙方进行设计、施工。装修项目为______________。
2.设计师将依照业主要求设计装修方案，并在竣工时交付给业主。
二、装修费用及支付方式：
1.装修费用合计______________，按照设计师提供的装修清单及预算来支付。
2.业主应在装修合同签订之日支付总款的____%作为定金，余款在工程竣工后支付。
三、装修质量保证：
1.设计师承诺所提供的设计和施工符合国家标准，并提供__________的质量保证期。
2.如因设计师的原因造成装修质量问题，设计师将承担相应的责任。
四、合同终止：
1.若因业主原因解除合同，已支付的定金不予退还。
2.若因设计师原因解除合同，设计师应退还已支付的全部费用，并承担相应的违约责任。
五、争议解决：
本合同如发生争议，双方应友好协商解决；协商不成的，提交相关仲裁机构解决。
六、其他约定事项：
1.本合同一式两份，业主和设计师各执一份，自签字盖章之日起生效。
2.未尽事宜，双方可另行协商解决。
甲方（盖章）： 乙方（盖章）：
签订日期：______________
英文正文：
Decoration Contract
Party A: (Homeowner) ______________
Party B: (Designer) ______________
In order to safeguard the interests of both parties, the following contract is hereby concluded:
General overview of decoration project:
1. The homeowner entrusts the designer, Party B, to design and construct the residential decoration project. The decoration project is ______________.
2. The designer will design the decoration scheme according to the homeowner's requirements and deliver it to the homeowner upon completion.
Decoration cost and payment method:
1. The total decoration cost is ______________, and it shall be paid according to the decoration list and budget provided by the designer.
2. The homeowner shall pay ____% of the total payment as a deposit on the day of signing the contract, with the balance to be paid upon completion of the project.
Quality guarantee for decoration:
1. The designer guarantees that the design and construction provided meet national standards, with a warranty period of ______________.
2. If there are quality issues with the decoration due to the designer's reasons, the designer shall assume corresponding responsibilities.
Termination of contract:
1. If the contract is terminated due to the homeowner's reasons, the deposit already paid shall not be refunded.
2. If the contract is terminated due to the designer's reasons, the designer shall refund all fees already paid and assume corresponding liability for breach of contract.
Dispute resolution:
In case of disputes arising from this contract, both parties shall resolve them through friendly negotiation; if no agreement can be reached, relevant arbitration institutions shall be engaged to settle the matter.
Other agreed matters:
1. This contract is made in duplicate, with the homeowner and designer each holding one copy, and it shall take effect from the date of signature and seal.
2. Matters not covered herein may be further negotiated and resolved by both parties.
Party A (Seal): __________
Party B (Seal): __________
Date of Signing: ______________
文章三：装修合同范本三
中文正文：
装修合同
甲方：（委托方）______________
乙方：（施工方）______________
鉴于甲方有装修需求，乙方需承接该装修项目，经双方友好协商，制定本合同如下：
一、装修工程范围及方式：
1.乙方应按照甲方要求进行装修设计和施工，装修项目为______________。
2.甲方应提供装修所需的基础设施和相应的配合，保障装修工程顺利进行。
二、装修费用及支付方式：
1.乙方提供的装修方案价为______________，按照设计清单中的各项费用结算。
2.甲方应在签订合同之日支付装修费用的____%作为定金，余款在工程完工后支付。
三、装修保修期：
1.乙方承诺提供的装修质量保修期为______________。
2.若装修出现质量问题，乙方将免费提供维修服务，保证装修质量符合国家标准。
四、违约责任：
1.若一方因故不能履行合同，应承担相应的违约责任。
2.如因不可抗力原因导致合同无法履行，双方可协商解除合同，无需承担违约责任。
五、争议解决：
本合同如有争议，双方应友好协商解决；协商不成的，适用本地法律解决。
六、其他约定事项：
1.本合同一式两份，甲方和乙方各执一份，合同自双方签字盖章之日起生效。
2.双方均保证合同的履行，确保装修工程的顺利进行，共同维护合同权益。
甲方（盖章）： 乙方（盖章）：
签订日期：______________
英文正文：
Decoration Contract
Party A: (Client) ______________
Party B: (Contractor) ______________
Whereas Party A has decoration needs, and Party B is willing to undertake the decoration project, after friendly negotiation between both parties, the following contract is established:
Scope and method of decoration project:
1. Party B shall carry out decorating design and construction as required by Party A, with the decoration project being ______________.
2. Party A shall provide the necessary infrastructure and cooperation for decoration and ensure the smooth progress of the decoration project.
Cost and payment method for decoration:
1. The price of the decoration scheme provided by Party B is ______________, to be settled based on the various expenses in the design list.
2. Party A shall pay ____% of the decoration cost as a deposit on the day of signing the contract, with the balance to be paid upon completion of the project.
Decoration warranty period:
1. Party B guarantees a decoration quality warranty period of ______________.
2. In the event of quality issues with the decoration, Party B will provide free repair services to ensure that the decoration quality meets national standards.
Breach of contract:
1. If either party is unable to fulfill the contract for reasons, they shall bear corresponding liability for breach of contract.
2. In the case of force majeure preventing the contract from being fulfilled, both parties may negotiate to terminate the contract without bearing liability for breach of contract.
Dispute resolution:
In case of disputes arising from this contract, both parties shall resolve them through friendly negotiation; if no agreement can be reached, local laws shall apply for resolution.
Other agreed matters:
1. This contract is made in duplicate, with Party A and Party B each holding one copy, and it shall take effect from the date of signature and seal by both parties.
2. Both parties guarantee the performance of the contract, ensuring the smooth progress of the decoration project and maintaining the rights and interests of the contract together.
Party A (Seal): __________
Party B (Seal): __________
Date of Signing: ______________
文章四：装修合同范本四
中文正文：
装修合同
甲方：（业主）______________
乙方：（装修公司）______________
鉴于业主甲方有装修需求，装修公司乙方愿意承接该装修项目，为确保双方权益，特订立装修合同：
一、装修项目概况：
1.业主将住宅装修工程委托给装修公司进行施工，装修项目为______________。
2.装修公司将提供相应的施工队伍和材料，保障装修工程的质量和进度。
二、装修费用及支付方式：
1.装修总费用为______________，业主应按照装修公司提供的预算结算。
2.业主应在签订合同之日支付总款的____%作为定金，余款在工程完工后支付。
三、工程保修期：
1.装修公司承诺提供______的工程保修期，保证装修工程的质量。
2.如装修出现质量问题，装修公司将提供免费的维修保养服务。
四、违约责任及争议解决：
1.若一方因故不能履行合同，应负相应的违约责任。
2.如发生合同纠纷，双方应友好协商解决，协商不成的，将提交相关仲裁机构解决。
五、其他约定事项：
1.本合同一式两份，业主及装修公司各执一份，自签字盖章之日起生效。
2.双方均保证合同内容的履行，并共同维护装修工程的顺利进行。
业主（盖章）： 装修公司（盖章）：
签订日期：______________
英文正文：
Decoration Contract
Party A: (Homeowner) __________
Party B: (Decoration Company) __________
Whereas Party A, the homeowner, has decoration needs, and Party B, the decoration company, is willing to undertake the decoration project, a decoration contract is hereby established to safeguard the interests of both parties:
Overview of decoration project:
1. The homeowner entrusts the decoration company with the construction of residential decoration, with the decoration project being ______________.
2. The decoration company shall provide the corresponding construction team and materials to ensure the quality and progress of the decoration project.
Cost and payment method for decoration:
1. The total decoration cost is ______________, and the homeowner shall settle the payment according to the budget provided by the decoration company.
2. The homeowner shall pay ____% of the total payment as a deposit on the day of signing the contract, with the balance to be paid upon completion of the project.
Engineering warranty period:
1. The decoration company guarantees a ______________ warranty period for the engineering, ensuring the quality of the decoration project.
2. In case of quality issues with the decoration, the decoration company shall provide free repair and maintenance services.
Liability for breach of contract and dispute resolution:
1. If either party is unable to fulfill the contract for reasons, they shall bear corresponding liability for breach of contract.
2. In the event of contract