电力运行维护合同模板.doc
《电力运行维护合同模板.doc》由会员分享,可在线阅读,更多相关《电力运行维护合同模板.doc(17页珍藏版)》请在咨信网上搜索。
1、精品文档 Contract No.: ICD/NW-2014-OM O&M Technical Service forICDAS BEKIRLI #2 UNIT OF (1+1) x 600MW POWER PLANTCONTRACTO&M Technical ServiceBetweenICDAS ELEKTRIK ENERJISI URETIM VE YATIRIM A.S.AndSHAANXI NORTHWEST POWER GENERATION CO.,LTD 30th June, 2014O&M Technical Service ContractO&M 技术服务合同Party A:
2、ICDAS ELEKTRIK ENERJISI URETIM VE YATIRIM A.S. (ICDAS)甲方:ICDAS ELEKTRIK ENERJISI URETIM VE YATIRIM A.S. (ICDAS)Party B: SHAANXI NORTHWEST POWER GENERATION CO.,LTD (CONTRACTOR)乙方:#股份有限公司(承包方)According to ICDAS requirement, CONTRACTOR organized the following operation persons as ICDAS employees, under
3、 the administration and management of ICDAS, to be working in ICDAS BEKIRLI #2 600MW power plant. 根据ICDAS的要求,承包方组织下列运行人员,作为ICDAS的雇佣人员,在ICDAS BEKIRKI #2 600MW电厂工作,接受ICDAS的监督和管理。 1.Person and Position List1.人员和职位列表Item No序号Department部门Position职位Number of Person (Qty)人员数1Management1 People管理人员1人Project
4、 Manager 项目经理12Operation29 People运行人员29名Turbine Operation Engineer 汽机专工1Boiler Operation Engineer 锅炉专工1Electrical Operation Engineer 电气专工1Chemical Operation Engineer 化学专工1I & C Engineer 热控专工1Shift Manager 值长4Boiler Operator 锅炉运行人员8Turbine Operator 汽机运行人员8Electrical Operator 电气运行人员 43others6 People其它
5、人员6名Interpreter 翻译4Cook 厨师2Total 总数36Notes说明:1) The shift managers, shifters, operators and translators will be working as 4 shifts (3 shifts in one day, and 1 shift as spare). Generally, the maintenance persons will be working in daytime.1)值长,专工,运行人员和翻译按照4班工作,(4班3倒),通常检修人员白天工作。2)The contract durati
6、on is decided as 6 months plus another 6 months optional.2)合同期限为6个月,可选择性的加6个月。ICDAS has right to extend the Contract for Bekirli #2 600MW unit for another 6 months as an option with the same unit price and conditions of this Contract, but ICDAS should inform CONTRACTOR 1 month before the end date of
7、 this contract. In case of such extension, ICDAS will be entitled to increase or decrease the number of staff.ICDAS 有权利再延长Bekiri #2 600MW机组的合同期6个月,作为本合同同等机组价格和条件的一种选择,但是ICDAS应该于此合同结束前一个月通知承包方。如果延期,ICDAS有权增加或者减少人员数量。2.Salary 2.薪酬The salary level: USD 3,500.00/ man-month (in words three thousand five
8、hundred US Dollars). 薪酬为:3500美元/人-月(口头价3千5百美元)The salary will be paid to CONTRACTOR before 10th of each month, to the account pointed by CONTRACTOR.薪酬于每月的10日前付给承包方指定的账户。Payment shall be settled to the following bank account.支付应结算到下列银行账户:Beneficiary: Shaanxi Northwest Power Generation Co.,Ltd收款人:#股份有
9、限公司Name of Bank: South Avenue Branch ,Xian City,China Construction Bank银行名:中国建设银行,西安,南大街支行A/C: 61014230000220100859账户:61014230000220100859SWIFT:PCBCCNBJSXXSWIFT号:PCBCCNBJSXXThe salary value is net value, without any tax or custom duty.薪酬价格为净值,不含任何税或者关税3.Benefits3.利益The above salary level includes:上述
10、薪酬标准包括:1)The site staffs oversea salary, allowance, subsidy and social security insurance.1)现场人员的海外工资,补贴,津贴及社会保险2)Food, office consumable, site transportation cost.2)食物,办公消耗,现场交通成本。3)Daily communication allowance.3)日常通讯津贴。4)Accident Insurance, max compensation is $200,000.00 dollars/per occurrence o
11、ne person.4)意外保险,最高补偿为200000美元/每发生一人5)Administrative fee, reasonable profit and tax5)管理费,合理的利润及税收6)Labor safety items, such as uniform, helmet, shoes, radios etc.6)劳动安全项目,如制服,安全帽,鞋及对讲机等。The above quote excludes:上述报价不包括:1)Party A shall provide Party B with work place, relevant facilities and website.
12、1)甲方应提供乙方工作场地,相关的设施及网络。2)Party A shall provide Party B with Convenient living condition, including convenient drinking water, shower water, kitchen device and place, natural gas for kitchen, electricity, internet, heating system, and necessary routine maintenance.2)甲方应提供乙方便捷的生活条件,包括,便利的饮用水,淋浴水,厨房设备和
13、场地,厨房用天然气,电力,互联网,供热系统及必要的日常维护。3)The visa application cost in Turkey shall be taken by Party A, and Party B shall provide all the documents of relevant staff.3)土耳其签证申请费用由甲方承担,乙方应提供相应人员的所有相关文件。4)The air ticket to and fro China (just one ticket per person per one year) shall be taken by Party A. 4)往返中国
14、机票(每年一次)由甲方承担。5)Party A shall be responsible to the transportation from the Istanbul airport to jobsite, and vice versa. 5)甲方应负责从伊斯坦布尔到达现场的往返交通。6)Party A shall be responsible for tax, residential permit, work permit (if has) under any titles required by the local authority.6)甲方应负责地方当局要求的相关居住许可,工作许可(
15、如果有)等相关许可。7)The starting time of the working period will be the date from Aug.01.2014.7)工作开始时间为2014年8月1日8)Medical service should be free of charge.8)医疗服务为免费的。9)Convenient working conditions.(Offices)9)便利的工作条(办公室)。10)Convenient inland transportation between living area and site, outside transportatio
16、n for shopping and traveling etc.10)便捷的交通设施往返于生活区域和现场, 以及方便的购物和旅行交通工具。11)Chinese Persons will work 8 hours/day (48 hours / week). If necessary, the persons will work overtime and ICDAS shall approve overtime working hours, extra salary (US$7 dollars/hour-person) must be paid by ICDAS at site at next
17、 salary day.11)中国人员每天工作8小时(48小时/周),如果需要人员加班工作,ICDAS应核准工作时间,加班薪酬(7美元/每人每小时),由ICDAS在下一个工作日,在现场支付。12)Working in Chinese legal holidays (10 days/year) will be considered as working overtime, the extra salary (US$7 dollars/hour- person) for all duty must be paid by ICDAS at site at next salary day.12)如果在
18、中国的法定休假工作(10天/年),视为加班工作,加班工资为(7美元/人/时)。ICDAS必须在下一个工作日,现场给予支付。13)Security in working and living area.13)工作及生活区的安全14)The site training of Turkish operators are included in this contract.14)土耳其运行人员的现场培训也包含在此合同中。4.Force Majeure 4.不可抗力aNeither CONTRACTOR nor ICDAS shall be liable for delay or failure of
19、performance under this contract where such failure or delay is caused by Force Majeure, being any event, occurrence or circumstance reasonably beyond control of either party, including but not limited to failure or delay caused by or resulting from Acts of God, strikes, fires, floods, earthquake, la
20、ndslide, typhoon, cyclone, storm , wars, ( whether declared or undeclared ), riots, delays of carriers due to breakdown imposed by any governmental authority ( including allocations, priorities, requisitions, quotas, and price controls).a承包商或者ICDAS受不可抗力影响无法履行合同规定的义务或者延迟履行的,任一方对此不承担任何责任。若发生超出任何一方合理控制
21、范围内的不可抗力事件、不可抗力发生以及不可抗力情况,包括但不限于天灾、罢工、火灾、水灾、地震、山体滑坡、台风、飓风、暴风雨、战争(已宣战或未宣战)、暴动、因政府当局颁布的限制性条款(包括配给、优先权、征用、配额及价格控制等)导致的运输延误等造成义务无法履行或义务履行延误。bIf the CONTRACTOR is prevented, hindered or delayed from or in performing any of its obligations under the Contract by an event of Force Majeure, then it shall not
22、ify the ICDAS in writing of the occurrence of such event and the circumstances thereof within fourteen (14) days after the occurrence of such event.b如果承包商因不可抗力而被妨碍、阻碍或者延迟履行其在本合同中的任一规定义务时,承包商应在不可抗力事件发生的十四(14)天内以书面形式通知ICDAS此类事件和情况的发生。cThe CONTRACTOR shall be excused from the performance or punctual pe
23、rformance of its obligations under the Contract for so long as the relevant event of Force Majeure continues and to the extent that the CONTRACTORs performance is prevented, hindered or delayed. The time for completion shall be extended reasonably.c如果相关不可抗力事件仍在发生,而且在一定程度上妨碍、阻碍或者延迟了承包商对义务的履行,则应予以免除承包
- 配套讲稿:
如PPT文件的首页显示word图标,表示该PPT已包含配套word讲稿。双击word图标可打开word文档。
- 特殊限制:
部分文档作品中含有的国旗、国徽等图片,仅作为作品整体效果示例展示,禁止商用。设计者仅对作品中独创性部分享有著作权。
- 关 键 词:
- 电力 运行 维护 合同 模板
1、咨信平台为文档C2C交易模式,即用户上传的文档直接被用户下载,收益归上传人(含作者)所有;本站仅是提供信息存储空间和展示预览,仅对用户上传内容的表现方式做保护处理,对上载内容不做任何修改或编辑。所展示的作品文档包括内容和图片全部来源于网络用户和作者上传投稿,我们不确定上传用户享有完全著作权,根据《信息网络传播权保护条例》,如果侵犯了您的版权、权益或隐私,请联系我们,核实后会尽快下架及时删除,并可随时和客服了解处理情况,尊重保护知识产权我们共同努力。
2、文档的总页数、文档格式和文档大小以系统显示为准(内容中显示的页数不一定正确),网站客服只以系统显示的页数、文件格式、文档大小作为仲裁依据,平台无法对文档的真实性、完整性、权威性、准确性、专业性及其观点立场做任何保证或承诺,下载前须认真查看,确认无误后再购买,务必慎重购买;若有违法违纪将进行移交司法处理,若涉侵权平台将进行基本处罚并下架。
3、本站所有内容均由用户上传,付费前请自行鉴别,如您付费,意味着您已接受本站规则且自行承担风险,本站不进行额外附加服务,虚拟产品一经售出概不退款(未进行购买下载可退充值款),文档一经付费(服务费)、不意味着购买了该文档的版权,仅供个人/单位学习、研究之用,不得用于商业用途,未经授权,严禁复制、发行、汇编、翻译或者网络传播等,侵权必究。
4、如你看到网页展示的文档有www.zixin.com.cn水印,是因预览和防盗链等技术需要对页面进行转换压缩成图而已,我们并不对上传的文档进行任何编辑或修改,文档下载后都不会有水印标识(原文档上传前个别存留的除外),下载后原文更清晰;试题试卷类文档,如果标题没有明确说明有答案则都视为没有答案,请知晓;PPT和DOC文档可被视为“模板”,允许上传人保留章节、目录结构的情况下删减部份的内容;PDF文档不管是原文档转换或图片扫描而得,本站不作要求视为允许,下载前自行私信或留言给上传者【精***】。
5、本文档所展示的图片、画像、字体、音乐的版权可能需版权方额外授权,请谨慎使用;网站提供的党政主题相关内容(国旗、国徽、党徽--等)目的在于配合国家政策宣传,仅限个人学习分享使用,禁止用于任何广告和商用目的。
6、文档遇到问题,请及时私信或留言给本站上传会员【精***】,需本站解决可联系【 微信客服】、【 QQ客服】,若有其他问题请点击或扫码反馈【 服务填表】;文档侵犯商业秘密、侵犯著作权、侵犯人身权等,请点击“【 版权申诉】”(推荐),意见反馈和侵权处理邮箱:1219186828@qq.com;也可以拔打客服电话:4008-655-100;投诉/维权电话:4009-655-100。